Effective Date: 01 January, 2021
Welcome to Ocean Designs Studio (“Company”, “we”, “our”, “us”). These Terms and Conditions govern your use of our website https://oceandesignstudio.in/
(“Website”) and our interior design services. By accessing or using our Website or services, you agree to be bound by these Terms and Conditions.
1. Use of Website
By using this Website, you agree:
- To use the Website for lawful purposes only
- Not to misuse, copy, or distribute content without permission
- Not to attempt unauthorized access to our systems
- Not to engage in activities that disrupt Website functionality
We reserve the right to restrict or terminate access to the Website if these terms are violated.
2. Services
Ocean Design Studio provides interior design consultancy and related services, including but not limited to:
- Residential interior design
- Commercial interior design
- Space planning
- Design consultation
- Project coordination (if applicable)
All services are subject to separate agreements, quotations, and project contracts where applicable.
3. Quotations and Payments
- All quotations provided are valid for a limited period as mentioned in the proposal.
- Project pricing may vary depending on scope changes.
- Payment terms, milestones, and schedules will be defined in the official project agreement.
- Delayed payments may result in project delays or suspension of services.
4. Intellectual Property
All content on this Website, including:
- Images
- Designs
- Layouts
- Graphics
- Text
- Logos
are the intellectual property of Ocean Designs Studio unless otherwise stated.
You may not reproduce, distribute, or use any content without prior written permission.
Project designs created by us remain our intellectual property unless otherwise agreed in writing.
5. Project Execution & Third Parties
- We act as a design consultant unless specifically contracted for execution.
- We are not liable for delays, workmanship issues, or damages caused by third-party contractors unless explicitly agreed in writing.
- Material availability and pricing are subject to market conditions.
6. Limitation of Liability
- We shall not be liable for indirect, incidental, or consequential damages.
- We are not responsible for Website downtime, technical errors, or inaccuracies.
- Our liability, if any, shall be limited to the fees paid for the specific service in question.
7. Website Accuracy
We strive to ensure all information on the Website is accurate and up to date. However:
- We do not guarantee completeness or accuracy at all times.
- Content may be updated without prior notice.
Images shown on the Website are for portfolio and illustrative purposes.
8. Third-Party Links
Our Website may contain links to third-party websites or social media platforms. We are not responsible for their content, policies, or practices.
9. Cancellation & Refund Policy
- Cancellation terms will be specified in the project agreement.
- Any refund, if applicable, will be processed as per agreed contractual terms.
- Advance payments may be non-refundable depending on project stage and resources allocated.
10. Privacy
Your use of this Website is also governed by our Privacy Policy.
11. Force Majeure
- Natural disasters
- Government restrictions
- Supply chain disruptions
- Labor strikes
12. Governing Law
These Terms shall be governed by and construed in accordance with the laws of India.
Any disputes shall be subject to the jurisdiction of the courts of [Insert City, e.g., Ahmedabad, Gujarat].
13. Changes to Terms
We reserve the right to modify these Terms and Conditions at any time. Updated versions will be posted on this page with a revised Effective Date.
14. Contact Information
For any questions regarding these Terms and Conditions, please contact:
Ocean Designs Studio
- Website: https://oceandesignstudio.in/
- Email: inquires@oceandesignstudio.in
- Phone: +91 97276 11169
- Address: B-405, Sankalp Iconic Tower, Bopal Ambli Road, Ahmedabad, Gujarat – 380058.